01/25/2023 ZONING BOARD OF APPEALS Decision

Home Browse Search

Town of Mashpee 16 Great Neck Road North Mashpee, MA 02649 MASHPEE ZONING BOARD OF APPEALS DECISION FOR A MODIFICATION EXTENSION OF SP-2015-33, SP-2019-36 AND SP-2020-28 MOD-2023-08 Petitioner, Triple M Management Bk.:29370 Owner of Record: Triple M Management Company, LLC Pg.: 175 29 Echo Road (Map 19 Parcel 3-9) and, Owner of Record: Triple M Management Company, LLC Bk.: 33210 41 Echo Road (Map 19 Parcel 3-8) Pg.: 113 Mashpee, MA 02649 A Petition was filed on December 19, 2022 by Petitioner, 3M Ventures, Inc., d/b/a Triple M Management Company,LLC requesting a modification under§174-24(C)(9)(c)(e)of the Zoning Bylaws, and condition #5 of the Special Permit Decision SP-2020-28 to extend the date for completion of construction from its previously extended date of February 26, 2023 to August 31, 2023 on property located in the I-1 and Light Industrial Overlay Zoning Districts, Map 19 Parcels 3-8 and 3-9, Mashpee, MA. (Owner of record: Triple M. Management Company, LLC. Notice was duly given to abutters in accordance with Massachusetts General Laws Chapter 40A. Notice was given by publication in The Mashpee Enterprise,a newspaper of general circulation in the Town of Mashpee, on January 6,2023 and January 13,2023 a copy of which is attached hereto and made a part hereof. The Mashpee Zoning Board of Appeals issues this Decision pursuant to the provisions of Massachusetts General Laws Chapter 40A §9 and the Town of Mashpee Zoning By-laws. Public Hearings were held on the Petition at the Mashpee Town Hall on Wednesday, January 25, 2023 at which time the following members of the Board of Appeals were present; Chairman, Jonathan Furbush,Vice Chairman,William Blaisdell,Board Members,Ron Bonvie,and Associate Members, Charles Reidy and Brad Pittsley. Attorney Christopher Kirrane represented Triple M Management Company. Also present was Kevin O'Reilly with Triple M. The applicant was before the Board last year and requested a Modification to the Special Permit and set a deadline for completing the expansion to August 26, 2022.Due to construction and engineering delays,the applicant requested an extension to February 26, 2023. Unfortunately due to the weather conditions, project delays, and contractor delays, the applicant is asking for another extension until August 31, 2023. Attorney Kirrane submitted pictures of the building construction that is currently moving forward. I